No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 01.05.26
Consideration of Artificial Intelligence in Arbitration Terms of Reference
As artificial intelligence (AI) continues to evolve and integrate into various aspects of legal practice, counsel and arbitral tribunals drawing up their Terms of Reference (TOR) establishing the terms of the dispute being referred to arbitration and also formulating their procedural orders should consider the implications of AI. This client alert highlights the importance of addressing AI in TOR negotiations and provides an overview of likely topics international arbitration practitioners can expect to treat in TORs and procedural orders.
Client Alert | 4 min read | 12.31.25
Raising the Bar: New York Expands Consumer Protection Law with FAIR Business Practices Act
Client Alert | 4 min read | 12.30.25
Client Alert | 6 min read | 12.30.25
Investor Advisory Committee Recommends SEC Disclosure Guidelines for Artificial Intelligence
