CAS Price Adjustments Limited To "Affected" Contracts
Client Alert | 1 min read | 06.16.10
In Donley v. Lockheed Martin Corp. (June 10, 2010) (litigated by Crowell & Moring), the Federal Circuit affirmed the ASBCA's decision that a CAS-covered contract that was completely repriced with full disclosure after a change in accounting was not "affected" by the change and was not subject to price adjustment to reflect the impact of the change -- an argument that could also preclude price adjustments on task orders that are negotiated without reliance on cost accounting information under CAS-covered IDIQ contracts. The Court rejected the Justice Department's arguments that the repriced contract was "affected" by the change either because it had been modified rather than completely terminated and re-awarded or because the PCO's agreement to a new price constituted an impermissible "waiver" of the ACO's exclusive right to determine the impact of an accounting change.
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.10.26
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
