Union Obtains Protest Relief In District Court
Client Alert | less than 1 min read | 03.08.06
In Nat'l Treasury Employees Union v. IRS (D.D.C., Feb. 22, 2006), the union successfully challenged the decision of IRS to contract out mailroom functions without holding a public-private competition as required by the 2004 IRS appropriations act. Of most interest was the finding of the district court that the provisions of 28 U.S.C. 1491(b) giving the Court of Federal Claims exclusive jurisdiction over protests did not apply because the union was not an "interested party" under that provision, i.e., an actual or prospective bidder.
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.10.26
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
