T4D Slam Dunked To T4C When Contractor Misled
Client Alert | less than 1 min read | 07.30.04
In Divecon Services, LP, the GSBCA overturned the National Oceanic and Atmospheric Administration’s termination for default of a contract to charter a remotely operated vehicle (ROV), despite the ROV’s failure to operate properly or obtain the ultimately desired data. The board reasoned that NOAA had waived any contract completion date by (1) encouraging the contractor right up to the day of termination (the originally specified contract completion date) to incur substantial costs for ROV repair work necessary for continued contract performance, (2) failing to set a new completion date, and (3) leading the contractor during last minute negotiations to believe that agreement on a contract extension was a “slam dunk.”
Insights
Client Alert | 4 min read | 04.01.26
On March 25, 2026, in Cox Communications, Inc. v. Sony Music Entertainment, the U.S. Supreme Court reversed a $1 billion verdict against Cox. The judgment was the result of a jury trial in which Sony claimed that Cox was liable for contributory copyright infringement because it knew that its customers were using its service to infringe yet did not respond with sufficient diligence to prevent that infringement.
Client Alert | 5 min read | 04.01.26
Client Alert | 7 min read | 04.01.26
Client Alert | 5 min read | 03.31.26
Washington State Bans and Voids Most Noncompetes, Narrows Nonsolicits
