Sample Tasks Must Be Reasonable Proxy For Entire Contract
Client Alert | 1 min read | 06.08.06
Holding that a cost realism analysis must provide a reasonable basis for estimating the cost to the government of an offeror's performance, in Metro Machine Corp . (May 3, 2006, http://www.gao.gov/decisions/bidpro/ 2978792.pdf) GAO overturned the agency's cost realism evaluation because, while sample tasks can provide a reasonable basis to assess the relative costs of competing proposals, the sample tasks used by the agency in this case were not representative of the contract work. The awardee had proposed a subcontractor with labor rates higher than the prime contractor's to perform a significant portion of the work, but, because that subcontractor had not been included in the proposed solution for any of the sample tasks, the subcontractor's high labor rates were nowhere reflected in the cost realism evaluation.
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.10.26
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
