Punctilious Performance Required For Recovery
Client Alert | less than 1 min read | 03.04.05
Ignoring that the government's own failure to have drawings ready so that performance could begin made the contractor's failure to have a required certificate of insurance immaterial, the Federal Circuit in Singleton Contracting Corp. v. Harvey (Jan. 26, 2005) found concurrent cause for delay and denied delay damages to the contractor. The lesson for contractors is to meet all of your contract requirements that you reasonably can, even when the circumstances may seem to make them superfluous.
Insights
Client Alert | 4 min read | 12.04.25
District Court Grants Preliminary Injunction Against Seller of Gray Market Snack Food Products
On November 12, 2025, Judge King in the U.S. District Court for the Western District of Washington granted in part Haldiram India Ltd.’s (“Plaintiff” or “Haldiram”) motion for a preliminary injunction against Punjab Trading, Inc. (“Defendant” or “Punjab Trading”), a seller alleged to be importing and distributing gray market snack food products not authorized for sale in the United States. The court found that Haldiram was likely to succeed on the merits of its trademark infringement claim because the products at issue, which were intended for sale in India, were materially different from the versions intended for sale in the U.S., and for this reason were not genuine products when sold in the U.S. Although the court narrowed certain overbroad provisions in the requested order, it ultimately enjoined Punjab Trading from importing, selling, or assisting others in selling the non-genuine Haldiram products in the U.S. market.
Client Alert | 21 min read | 12.04.25
Highlights: CMS’s Proposed Rule for Medicare Part C & D (CY 2027 NPRM)
Client Alert | 11 min read | 12.01.25
