Novation Trap For The Unwary
Client Alert | 1 min read | 02.04.11
In Raytheon Co. v. U.S. (Jan. 26, 2011), the Court of Federal Claims held that a contractor's claim for the pension cost adjustment due under CAS 413 for pension plans with funding deficits at the time of a "segment closing" could be barred by the standard language required in novation agreements providing that the contractor "waives any claims and rights against the Government that it now has or may have in the future in connection with the [novated] contracts." Because the Government takes the position that its agreement to novate contracts is completely within the untrammeled discretion of the Government, the Government could effectively negate the requirements of CAS 413 if this decision is correct by refusing to novate contracts unless the contractor agrees to waive its rights to an adjustment under CAS 413.
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.10.26
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
