No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 5 min read | 07.28.26
Data Centers in the Crosshairs: The Plaintiffs' Bar Has Begun Filing New Claims Using Old Tricks
The rapid buildout of AI infrastructure has placed data centers at the heart of a new and expanding wave of class action litigation. Over the past several months, plaintiffs’ firms with significant experience in mass tort and environmental class actions have begun recruiting plaintiffs and filing lawsuits against data center operators, alleging that noise generated by their facilities — from cooling systems, diesel generators, and HVAC equipment — constitutes a public and private nuisance and reflects actionable negligence. Companies currently operating or constructing data centers near residential communities should treat this as a material and growing legal risk.
Client Alert | 2 min read | 07.24.26
GAO Finds That Challenge to Agency’s Failure to Comply With DFARS Requirement Comes Too Late
Client Alert | 3 min read | 07.23.26
