1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 9 min read | 08.02.26

The 2026 ICC Arbitration Rules: A New Era

The International Chamber of Commerce (ICC) has released its revised 2026 Arbitration Rules (the 2026 Rules), which entered into force on 1 June 2026. The 2026 Rules apply to any arbitration commenced on or after 1 June 2026, unless the parties have agreed otherwise. The revisions were driven by increased competition among arbitral institutions—illustrated by recent amendments to the Singapore International Arbitration Centre (SIAC) Rules in August 2025 and the anticipated update to the London Court of International Arbitration (LCIA) Rules....