No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 02.20.26
SCOTUS Holds IEEPA Tariffs Unlawful
On February 20, 2026, the Supreme Court issued a pivotal ruling in Trump v. V.O.S. Selections, negating the President’s ability to impose tariffs under IEEPA. The case stemmed from President Trump’s invocation of IEEPA to levy tariffs on imports from Canada, Mexico, China, and other countries, citing national emergencies. Challengers argued—and the Court agreed—that IEEPA does not delegate tariff authority to the President. The power to tariff is vested in Congress by the Constitution and cannot be delegated to the President absent express authority from Congress.
Client Alert | 7 min read | 02.20.26
Section 5949 Proposed Rule Puts the FAR Council's Chips on the Table
Client Alert | 5 min read | 02.20.26
Trump Administration Pursues MFN Pricing for Prescription Drugs
Client Alert | 4 min read | 02.19.26
Proposed NY Legislation May Mean Potential Criminal Charges for Unlicensed Crypto Firms
