No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 08.25.26
DOJ Signals Increased Antitrust Scrutiny of Algorithmic Pricing in Willow Bridge Decision
Algorithmic pricing tools commonly used by businesses to increase efficiency and profits are under increasing antitrust scrutiny. This summer, federal regulators, state attorneys general, and state legislatures grappled with competing businesses providing nonpublic, competitively sensitive data to common algorithmic platforms. The Third Circuit deepened an emerging circuit split with the Ninth Circuit on algorithmic pricing liability, reviving antitrust claims against Atlantic City casino-hotels in a decision with direct implications for any company that uses a common pricing platform. See Crowell’s recent client alert. And New Jersey enacted two landmark laws—the FAIR Act and the Fair Price Protection Act—directly regulating algorithmic rent-setting and surveillance pricing. See Crowell’s recent client alert.
Client Alert | 4 min read | 08.25.26
Recent Court Decision Highlights Effectiveness of “Second Bite” Protests
Client Alert | 5 min read | 08.21.26
FTC Proposes Enforcement Policy Statement on Personalized Pricing: What Businesses Need to Know
