No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 08.27.26
FCC Clarifies Covered List for Power Inverters and Advanced Robotic Devices
On July 28, 2026, the Federal Communications Commission (FCC) updated its Covered List — established through the Secure and Trusted Communications Networks Act — to include foreign-produced connected power inverters and advanced robotic devices, following an executive branch national security determination that they “pose unacceptable risks to the national security of the United States or the safety and security of United States persons.” Equipment on the Covered List is ineligible for FCC equipment authorization, effectively prohibiting the import, sale, or marketing of those products without an exception or approval.
Client Alert | 5 min read | 08.26.26
D.C. Circuit Upholds Designation of PFOA and PFOS as CERCLA Hazardous Substances
Client Alert | 5 min read | 08.26.26
Client Alert | 6 min read | 08.26.26
The Risky Fifth: A Long Hot Summer in Congressional Jurisprudence
