No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 04.20.26
EU Pharma Package: The “Bolar” Exemption Compromise Proposal
In our sixth alert in this EU Pharma Package Series, we provided an analysis of the history and interpretation issues for another highly debated topic: the “Bolar” exemption.
Client Alert | 8 min read | 04.17.26
CMS Finalizes CY 2027 Medicare Advantage and Part D Rule: Key Implications for Plan Sponsors
Client Alert | 1 min read | 04.17.26
Client Alert | 3 min read | 04.17.26
