No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 06.23.26
EPA Hands Over AI Data Center Regulation to States and Communities to Develop Best Practices
The nation’s power grid and infrastructure are facing increased pressure from artificial intelligence (AI) data centers, prompting new questions around environmental regulatory design and compliance. As technology companies race to build and expand new data center factories, they face a web of permitting requirements as well as potential community opposition, and environmental litigation — all against a backdrop of rapid and still-evolving agency guidance.
Client Alert | 3 min read | 06.22.26
Client Alert | 4 min read | 06.17.26
From Checkout To Opt-Out: The EU Withdrawal Button Is Here – What E-Commerce Businesses Need To Know
Client Alert | 6 min read | 06.17.26
