No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 14 min read | 03.13.26
AI for Government: 7 Days for Contractor Comments on GSA Proposed Contract Clause for AI Systems
On March 6, 2026, the General Services Administration (GSA) issued a significant proposed contract clause, GSAR 552.239-7001, Basic Safeguarding of Artificial Intelligence Systems (“Clause”), for inclusion in GSA Schedule solicitations and contracts for AI capabilities. The proposed clause would impose substantial new requirements related to AI sources, intellectual property rights, data use, change management, and performance standards. The Clause would also take precedence over any other contract terms (including commercial licensing terms) related to AI, including a Seller’s terms of sale and service to which the Government had previously agreed. GSA requests comments by March 20, 2026.
Client Alert | 3 min read | 03.12.26
DOJ Releases First-Ever Department-Wide Corporate Enforcement and Voluntary Self-Disclosure Policy
Client Alert | 3 min read | 03.12.26
