No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 5 min read | 03.30.26
Déjà Vu? New Executive Order Outlines Restrictions on Contractor and Subcontractor DEI Activity
On March 26, 2026, President Trump issued an executive order (EO) titled Addressing DEI Discrimination by Federal Contractors. The EO declares diversity, equity, and inclusion (DEI) “activities” “unethical and often illegal,” and imposes new obligations on federal contractors and subcontractors related to DEI programming. Contractors that do business with the federal government — or that work as subcontractors for companies that do — should review the EO closely to determine the extent to which they are compliant with the new requirements.
Client Alert | 5 min read | 03.30.26
Firewall Up: FCC Bars Foreign-Made Routers in New Covered List Update
Client Alert | 4 min read | 03.30.26
Landmark Verdicts Against Meta and YouTube Signal New Era of Social Media Platform Liability
Client Alert | 5 min read | 03.30.26
The EU Pharma Package: The Transferable Exclusivity Voucher Compromise Proposal
