No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 05.21.26
A New Playbook for M&A in the EU: The European Commission's Draft Merger Guidelines - 10 Key Changes
On 30 April 2026, the European Commission published draft merger guidelines that will replace both the 2004 Horizontal Merger Guidelines and the 2008 Non-Horizontal Merger Guidelines, consolidating them into a single analytical framework.
Client Alert | 3 min read | 05.21.26
Judge Jennifer Choe-Groves Takes Over Several DNJ Hatch-Waxman Cases
Client Alert | 7 min read | 05.19.26
American and Allied Cyber Agencies Issue First Joint Guidance on Securing Agentic AI
Client Alert | 3 min read | 05.19.26
