1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 7 min read | 10.27.26

New Developments in DOJ Whistleblower Policies and HHS Disclosures: Key Takeaways for General Counsel, Chief Compliance Officers, and Boards

On October 20, 2026, the U.S. Department of Justice’s (DOJ) National Fraud Enforcement Division announced a new whistleblower rewards initiative, the Fraud Whistleblower Incentive Program (WHIP). Assistant Attorney General Colin M. McDonald issued a directive earlier this month directing Division leadership to design and implement policies and programs that incentivize whistleblowers to bring forward credible information pertaining to fraud. The new WHIP incentive pays awards of $10,000 to $30,000 for qualifying tips at or around the time criminal charges are filed or unsealed, rather than years later at case resolution....