No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 5 min read | 09.02.26
DOJ’s Civil Rights Fraud Initiative Claims Another DEI-Related FCA Settlement
On Tuesday, August 25, 2026, the U.S. Department of Justice (DOJ) announced that Deloitte LLP and several of its subsidiaries agreed to pay, collectively, $21.5 million to resolve allegations that Deloitte violated the False Claims Act (FCA) by failing to comply with new anti-discrimination requirements incorporated into its federal contracts, by discriminating against employees and applicants on the basis of race and sex, and by allocating and seeking reimbursement for costs related to those practices under its federal government contracts. This resolution is the second of its kind under DOJ’s recently launched Civil Rights Fraud Initiative, following a similar settlement by IBM in April 2026.
Client Alert | 4 min read | 09.02.26
Client Alert | 7 min read | 09.02.26
OCC and FDIC Redefine “Unsafe or Unsound Practices”: The New Supervisory Framework for Banks
Client Alert | 4 min read | 09.02.26
The CSC Is Investigating: What Its New NIL Enforcement Memo Means for Institutions
