No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 2 min read | 02.03.26
CMS Doubles Down on RADV Audit Changes
On January 27, 2026, the Centers for Medicare and Medicaid Services (CMS) released a Health Plan Management System (HPMS) memo that provided a long-awaited update on how the agency plans to approach previously announced Risk Adjustment Data Validation (RADV) audits for Payment Years (PY) 2020-2024. The memo is the agency’s most comprehensive statement on the subject since September 25, 2025, when the Northern District of Texas vacated the 2023 RADV Final Rule. The memo makes clear that, while CMS has made certain operational adjustments in response to concerns expressed by Medicare Advantage Organizations (MAOs), the agency is largely pressing forward with the accelerated audit strategy announced in May 2025.
Client Alert | 2 min read | 02.03.26
Sedona Model Jury Instructions for DTSA: A Step Forward—But Questions Remain
Client Alert | 7 min read | 01.30.26
CMS Proposes CY 2027 Growth Rate and Changes to Risk Adjustment for Medicare Parts C and D
Client Alert | 4 min read | 01.30.26
Optimum’s Shot Across the Bow: An Antitrust Challenge to Cooperation Agreements
