No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 2 min read | 06.29.26
When Trade Secret Theft Becomes Racketeering: What the Fifth Circuit’s New Ruling Means
RICO was built for the mob. But Congress gave trade secret victims access to it in 2016, and a recent U.S. Court of Appeals for the Fifth Circuit decision shows that access is real.
Client Alert | 7 min read | 06.26.26
Federal Roundup: Updates for PBMs and Medicare Advantage Organizations
Client Alert | 6 min read | 06.26.26
Client Alert | 4 min read | 06.25.26
Twin Executive Orders Seek to Spur Quantum Leap in Technology and Cybersecurity
