No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 07.31.26
On July 23, 2026, the U.S. Department of Justice’s Antitrust Division announced that it will again use targeted Second Request investigations and released a revised Model Timing Agreement, another signal that this Antitrust Division continues to take a more business friendly approach toward merger review. The model introduces an optional “Expedited Consideration” process that gives merging parties the option to address discrete competitive concerns identified by the DOJ before undertaking full Second Request compliance.
Client Alert | 5 min read | 07.28.26
Data Centers in the Crosshairs: The Plaintiffs' Bar Has Begun Filing New Claims Using Old Tricks
Client Alert | 2 min read | 07.24.26
GAO Finds That Challenge to Agency’s Failure to Comply With DFARS Requirement Comes Too Late
