No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 3 min read | 02.13.26
In October 2024, the FTC adopted a final rule that substantially modified the HSR form, requiring new categories of information and documents. The final rule was the most significant overhaul of the HSR premerger notification requirements in decades. The new requirements imposed additional time and expense on merging parties, with the FTC estimating that the new form would likely take triple the amount of time to complete than the previous form. Numerous groups, including the U.S. Chamber of Commerce, sued to challenge the rule.
Client Alert | 12 min read | 02.13.26
What Organ Procurement Organizations Need to Know About CMS's New Proposed Rule
Client Alert | 9 min read | 02.12.26
Client Alert | 3 min read | 02.12.26
