No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 9 min read | 10.21.26
The life sciences sector is uniquely vulnerable to the inherent risks of AI-generated evidence in drug development and discovery. This client alert focuses on five core challenges: hallucinations, skewed predictions from unrepresentative training data, the opacity of AI reasoning, input sensitivity that undermines reproducibility, and adversarial manipulation of training data. To address these risks, companies should use experimental validation and human oversight as the common legal and regulatory safety net. This entails among other measures auditing AI outputs, characterizing training data, and structural oversight. Companies also should prepare for evolving frameworks and guidance from the U.S. Food and Drug Administration (FDA) and the European Union (EU) that address use of AI in drug discovery and development .
Client Alert | 2 min read | 10.21.26
Client Alert | 3 min read | 10.21.26
Private Investigations Act Series: Temporal, material and territorial scope
Client Alert | 7 min read | 10.21.26
