1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 5 min read | 07.01.26

What U.S. Patent Holders Need to Know About Inequitable Conduct Right Now

If a court finds that a patent applicant intentionally misrepresented or withheld material information from the USPTO with the intent to deceive, the consequences are severe, leading to unenforceability of the entire patent (and likely any later patents claiming priority to the unenforceable patent)....