1. Home
  2. |Insights
  3. |NAICS Challengers at Court Must First Exhaust Administrative Remedies

NAICS Challengers at Court Must First Exhaust Administrative Remedies

Client Alert | less than 1 min read | 04.27.15

On April 22, 2015, the Federal Circuit ruled in Palladian Partners, Inc. v. U.S. that, although the Court of Federal Claims has jurisdiction to review challenges to NAICS code decisions made by the SBA's Office of Hearing and Appeals (OHA), in order for an offeror to challenge such a decision at the court, the offeror had to have participated in the appeal at OHA brought by a different offeror. Here, because the offeror failed to do so, the offeror had not exhausted its administrative remedies, and the case was remanded to be dismissed.


Insights

Client Alert | 1 min read | 08.10.26

ASBCA Denies Government Motion to Dismiss, Providing Key Guidance on Contractor Claim Standards Post-ECC International

In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer. ...