German Bundesgerichtshof (Federal Supreme Court) Provides Guidance on the Definition of the De Minimis Clause in Determining Whether a Merger Is Subject to German Merger Control
Client Alert | 1 min read | 12.17.07
Last Friday, in a controversial and long-awaited decision, the German Bundesgerichtshof clarified the de minimis merger filing exception in Germany. In Germany, merger filings are required if the thresholds are met and the concentration has an impact on the market unless the market affected by the merger is a de minimis market. What constitutes a de minimis market has been the subject of considerable debate. In its judgment the Bundesgerichtshof clarifies the so-called “minor market clause” (section 35 (2), no. 2 Act against Restraints of Competition (“ARC”)).
In order to be considered de minimis, two factors must be met. First, the affected market must be one in which goods or commercial services have been offered for at least five years. By requiring the market to be in existence for at least five years, newly developed and still expanding markets are subject to German merger control. Second, in order for a merger to be exempt from German merger control under the de minimis exception, the annual sales volume for the relevant market must have been less than € 15 million in the previous calendar year. Since July 1, 2005, the German Federal Cartel Office (Bundeskartellamt) has interpreted this second requirement rather broadly, taking the position that the relevant market, for purposes of determining sales volume, may - as the case may be - extend beyond Germany.
Based on this interpretation, the Bundeskartellamt prohibited a concentration between Du Pont and Pedex & Co. GmbH because the total market turnover exceeded the sales volume threshold. The first instance court (Higher Regional Court of Düsseldorf), however, overturned this decision and held that, for the purpose of the de minimis or “minor market clause,” the geographical scope of the market can only extend to Germany. The Bundeskartellamt subsequently appealed this decision.
The Bundesgerichtshof upheld the decision of the Higher Regional Court of Düsseldorf. As in previous decisions, the Bundesgerichtshof upheld the practice of bundling groups of minor product markets together provided that the products are close neighbours (supply side substitutable), the market players are largely the same and the products are sold through the same distribution channel.
The Bundesgerichtschof decision has not yet been published.
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
