DoD White Paper Takes Aim at IR&D Costs
Client Alert | 1 min read | 09.01.15
While DOD's August 26 white paper "Enhancing the Effectiveness of Independent Research and Development" explains that the intent of new requirements it announced is "not to reduce the independence of IR&D investment selection, nor to establish a bureaucratic requirement for government approval prior to initiating an IR&D project," contactors have good reason to doubt that assertion. Most significantly for contractors, there will be a new DFARS rule under which, "beginning in FY 2017, DoD will require contractors to record the name of the government party with whom, and date when, a technical interchange took place prior to IR&D project initiation and to provide this information as part of the required IR&D submissions made to [DTIC]," and DCMA and DCAA "will use these DTIC inputs when making allowability determinations for IR&D costs."
Contacts
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.10.26
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
