1. Home
  2. |Insights
  3. |Court of International Trade Takes Jurisdiction Over Civil FCA Case

Court of International Trade Takes Jurisdiction Over Civil FCA Case

Client Alert | less than 1 min read | 08.04.05

Distinguishing its own precedent holding that it has no jurisdiction over civil FCA lawsuits brought by qui tam relators, the U.S. Court of International Trade (USCIT) recently held in U.S. v. Universal Fruits and Vegetables Corp., 2005 WL 1592953 (July 6, 2005), that it does have exclusive jurisdiction over non-qui-tam civil FCA actions brought by the government to recover unpaid customs duties. In this case involving government allegations that defendants avoided paying customs duties by making false statements to Customs officials, the USCIT confirmed a previous ruling of the Ninth Circuit that had transferred the matter to the USCIT for lack of subject matter jurisdiction.

Insights

Client Alert | 1 min read | 08.10.26

ASBCA Denies Government Motion to Dismiss, Providing Key Guidance on Contractor Claim Standards Post-ECC International

In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer. ...