1. Home
  2. |Insights
  3. |Contractor's Report to OIG Insufficient to Trigger Public Disclosure Bar

Contractor's Report to OIG Insufficient to Trigger Public Disclosure Bar

Client Alert | less than 1 min read | 03.27.14

In U.S. ex rel Saunders v. Unisys Corp. (E.D. Va.), the court found that the relator's FCA claim was not precluded by the public disclosure bar despite the defendant providing its internal investigation report to OIG because (1) the report failed to reveal allegations or transactions creating an inference of fraud (its conclusion that the alleged fraudulent billing practices were "unacceptable" was not enough) and (2) it was made available only to the DOD IG and the government agency overseeing the contract and not the general public.


Insights

Client Alert | 1 min read | 08.10.26

ASBCA Denies Government Motion to Dismiss, Providing Key Guidance on Contractor Claim Standards Post-ECC International

In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer. ...