1. Home
  2. |Insights
  3. |Contractor Gets "Second Bite" When Final Decision Reconsidered

Contractor Gets "Second Bite" When Final Decision Reconsidered

Client Alert | less than 1 min read | 08.03.15

In LRV Envtl., Inc. (July 14, 2015), the ASBCA found that "reconsideration" of a CO's final decision resets the 90-day clock for a CDA appeal. The CO had issued a final decision, but subsequently reconsidered a portion of it on its own motion, leading the board to conclude that "the decision was not truly final" prior to the reconsideration and so the contractor's 90-day appeal window ran from the latter decision.


Insights

Client Alert | 1 min read | 08.10.26

ASBCA Denies Government Motion to Dismiss, Providing Key Guidance on Contractor Claim Standards Post-ECC International

In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer. ...