Congress Enacts Appropriations Restriction Relating to Felony Convictions
Client Alert | 1 min read | 01.18.12
As is discussed in more detail in a blog posting, the recently enacted Consolidated Appropriations Act of 2012 includes provision in five of the nine individual bills covered in the Act prohibiting the use of funds “to enter into a contract, memorandum of understanding, or cooperative agreement with, make a grant to, or provide a loan or loan guarantee to, any corporation” with a felony conviction within the preceding 24 months, unless the agency has considered suspension or debarment and made a determination that no further action is necessary. This provision is almost sure to create uncertainty because Congress did not create a uniform standard, but instead included language in only certain individual appropriation acts, with substantial variances between the different provisions (e.g., some provisions only apply if the corporation is convicted while other also include officers or agents of the corporation).
Contacts
Insights
Client Alert | 1 min read | 08.10.26
In Appeal of Bahadir (a C&M case), the Armed Services Board of Contract Appeals denied the government’s motion to dismiss in its entirety, ruling in favor of the contractor on both key issues raised by the government. The case arises from a contract for construction work at Al Udeid Air Base in Qatar, under which Appellant alleged government-caused delay and filed certified prolongation claims using a “windows analysis” methodology. The government moved to dismiss, arguing that Appellant failed to state a sum certain for each of what the government characterized as 38 distinct claims, and separately that four claims had not been properly presented to the Contracting Officer.
Client Alert | 4 min read | 08.10.26
Client Alert | 4 min read | 08.07.26
Missouri AG Sues Kansas City Over Race- and Sex-Based Contracting Program
Client Alert | 2 min read | 08.06.26
