1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 10 min read | 10.23.25

The EU’s Defense Readiness Roadmap and Omnibus: What are the Implications for Defense Procurement?

On October 16, 2025, the European Commission and the High Representative of the Union for Foreign Affairs and Security Policy presented their Defense Readiness Roadmap 2030 to the EU Member States. This comprehensive plan aims to strengthen European defense capabilities. It follows, and should be read together with, the Commission’s Defense Readiness Omnibus that was published in June 2025. The Omnibus contains a set of proposals to facilitate defense investments and boost EU Member States’ responsiveness to today’s security challenges....