No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 8 min read | 11.10.26
EU Simplifies Rules on Defense Procurement and Transfers of Defense-Related Products
The European Union has enacted its first major reform of the 2009 directives on defense procurement and intra-EU transfers of defense-related products. The amending directive, which has been adopted as part of the Defense Readiness Omnibus legislative package (also known as “Omnibus V”), aims to simplify and accelerate procedures both for buying defense- and security-related goods, and for transferring such goods between EU Member States.
Client Alert | 3 min read | 11.09.26
Client Alert | 4 min read | 11.09.26
Client Alert | 4 min read | 11.09.26
