No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 01.07.26
On December 17, 2025, the U.S. Food and Drug Administration (FDA) issued a request for information (RFI) on a proposal designed to help the FDA engage more directly with innovative, venture-backed companies focused on biotechnology, medical devices, AI, and regulatory technology.[i]The RFI includes 19 questions, with responses due by 2:00 p.m. ET on January 18, 2026.
Client Alert | 3 min read | 01.07.26
CMMC for AI? Defense Policy Law Imposes AI Security Framework and Requirements on Contractors
Client Alert | 3 min read | 01.07.26
New Year, Same CIPA Uncertainty – When Will the Appellate Courts Enter the Chat?
Client Alert | 11 min read | 01.07.26
