No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 3 min read | 01.13.26
Colorado Judge Quashes DOJ Gender-Related Care Subpoena
On January 5, 2026, District of Colorado Magistrate Judge Cyrus Chung issued a recommendation that the district court grant a motion to quash a Department of Justice (DOJ) administrative subpoena that sought records about the provision of gender-related care by Children’s Hospital Colorado (Children’s) in In re: Department of Justice Administrative Subpoena No. 25-1431-030, U.S. District Court for the District of Colorado, No. 1:25-mc-00063. The court concluded that the DOJ had failed to carry its “light” burden, noting that no other courts that had considered the more than 20 similar subpoenas issued by DOJ had ruled in the DOJ’s favor.
Client Alert | 7 min read | 01.13.26
Client Alert | 4 min read | 01.13.26
Client Alert | 4 min read | 01.07.26
