No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 08.17.26
Delayed Notification of Cyberattacks May Trigger HIPAA Breach Notification Rule
After identifying a ransomware attack in 2021, OSF Healthcare System waited until its forensic investigation had concluded before notifying the U.S. Department of Health and Human Services (HHS) — and the affected individuals — of the breach. The 110-day delay (nearly double the 60-calendar-day notification deadline mandated by the HIPAA Breach Notification Rule) triggered an investigation from HHS’s Office for Civil Rights (OCR). The health system’s investigation determined that protected health information (PHI) had been stolen.
Client Alert | 4 min read | 08.14.26
License to Hack? The White House Greenlights Private-Sector Offensive Cyber Operations
Client Alert | 4 min read | 08.13.26
Supreme Court Confirms Contractual Loss of Bargain Without Repudiatory Breach
Client Alert | 7 min read | 08.12.26
Developments in Canadian Investment Treaty Practice: New FIPA Between Canada and UAE in Force
