1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 6 min read | 08.11.26

Lending Against Digital Assets: Five Key Takeaways for Lenders After a Year of Regulatory and UCC Change

Over the past 18 months, the federal banking agencies have clarified supervisory expectations for banks’ crypto-asset activities, and several of the largest U.S. banks have announced programs accepting Bitcoin and Ether as loan collateral. Separately, on June 3, 2026, New York’s enactment of the 2022 amendments to the Uniform Commercial Code took effect, changing the rules governing the perfection of a security interest in digital asset collateral in New York, the jurisdiction whose law governs most institutional credit documentation. Together, these developments may create significant opportunities for lenders navigating the complexities to comply with the newly enacted statutes. This alert surveys the current landscape, from regulatory permissibility and perfection through custody, structuring, and compliance, for institutions active in this market or considering entering it....