No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 5 min read | 09.21.26
Congressional Letter Puts Spotlight on Unenforceable Secrecy Demands in Federal Subpoenas
When federal law enforcement agencies issue subpoenas to companies for information about their customers, the subpoenas or cover letters often contain boilerplate nondisclosure language. This language generally directs companies not to notify those customers and implies that there may be legal consequences for doing so. But as two lawmakers recently called out in a formal letter to the U.S. Supreme Court and the U.S. Government Accountability Office (GAO), this boilerplate language may not carry the force of law.
Client Alert | 8 min read | 09.18.26
Mining, Indigenous Consultation Rights, and Investment Treaty Protection: Part 2
Client Alert | 6 min read | 09.18.26
Client Alert | 3 min read | 09.18.26
What AI Companies Need to Know About NY AG's Whistleblower Push
