No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 6 min read | 07.17.25
On 11 July 2025, the European Commission published the final version of its Code of Practice for General-Purpose Artificial Intelligence (GPAI). This Code is meant to serve as a tool for GPAI model providers, helping them to comply with the transparency, copyright and security provisions governing general-purpose AI models as set out in the AI Act (arts. 53 and 55), which will become applicable on 2 August 2025. Adherence to the Code is on a voluntary basis.
Client Alert | 3 min read | 07.17.25
(Not the Funniest) Weekend Update: Recap of Recent Developments in the EU-US Tariff Dispute
Client Alert | 5 min read | 07.16.25
Client Alert | 8 min read | 07.16.25