No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 6 min read | 06.16.26
What United States v. Bankman-Fried Means for Health Care Fraud Defense
On the surface, United States v. Bankman-Fried is a case about the collapse of a cryptocurrency exchange. But the U.S. Court of Appeals for the Second Circuit’s recent opinion — affirming Samuel Bankman-Fried’s conviction on seven counts of fraud and conspiracy — carries important lessons that extend well beyond the world of digital assets.
Client Alert | 2 min read | 06.15.26
Kansas Federal Court Applies “Selective Enforcement” Theory to Reject DTSA Claim
Client Alert | 3 min read | 06.12.26
Client Alert | 4 min read | 06.12.26
Auto Dealers: The FTC Is Back in the Driver’s Seat — Warning Letters Signal Renewed Federal Scrutiny
