No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 10.22.26
Africa, MENA, and the Arbitration Act 2025: LCIA’s Latest Report
The LCIA's 2025 Annual Casework Report contains a finding that should command the attention of any business with commercial exposure to Africa or the Middle East. Participation from the Middle East and North Africa (MENA) rose to almost 15% of the LCIA's caseload in 2025, and the UAE alone is now the third most represented jurisdiction globally, overtaking every non-Anglophone jurisdiction in the world.[1] That shift did not happen in isolation. It coincided with the entry into force of the Arbitration Act 2025 (the 2025 Act) — the most significant reform of English arbitration law in a generation — and a dramatic surge in parties deploying the LCIA's procedural toolkit more aggressively than ever before.[2]
Client Alert | 4 min read | 10.22.26
CMS Proposal Would Require Extensive Provider Directory Changes in MA
Client Alert | 5 min read | 10.22.26
CMS Proposes Major Changes to MA, Part D, and PBM Requirements
Client Alert | 5 min read | 10.22.26
