No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 06.24.26
On June 17, 2026, the U.S. Department of Justice’s (DOJ( National Security Division (NSD) announced that it had issued a declination for Robert Bosch GmbH (Bosch) relating to potential violations of the Export Control Reform Act, 50 U.S.C. § 4819 (ECRA). Specifically, the DOJ declined to criminally prosecute Bosch’s violations of the Export Administration Regulations’ (EAR) Foreign Direct Product Rule (FDPR), which apparently resulted from two Bosch subsidiaries’ export of products and software manufactured with equipment that was the direct product of U.S. software or technology to Huawei Technologies Co., Ltd. and its “Entity List” affiliates, including Huawei Tech. Investment Co., Ltd., Hong Kong (collectively, Huawei). The same day, the U.S. Department of Commerce Bureau of Industry and Security (BIS) announced a parallel civil administrative settlement with Bosch.
Client Alert | 3 min read | 06.24.26
Client Alert | 4 min read | 06.23.26
EPA Hands Over AI Data Center Regulation to States and Communities to Develop Best Practices
Client Alert | 3 min read | 06.22.26
