No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 07.22.26
On July 17, 2026, the United States Department of Justice (DOJ) announced that it had entered into a Deferred Prosecution Agreement (DPA) with The Scoular Company (Scoular), an agricultural supply chain company based in Omaha, Nebraska, to resolve allegations that Scoular relied on customs brokers to bribe Mexican government officials to allow Scoular goods to pass customs inspections and be delivered to Mexico from the United States. As part of its resolution, Scoular agreed to pay a $9,769,521 criminal penalty and forfeit an additional $414,351. Scoular also committed to continue cooperating with DOJ on any ongoing or future criminal investigations, implement a compliance and ethics program designed to prevent and detect violations of the Foreign Corrupt Practices Act (FCPA), and periodically report to DOJ on remediation and implementation of compliance measures throughout the term of the DPA.
Client Alert | 4 min read | 07.22.26
Ghost Advertising: Compliance Takeaways From the Gymshark Influencer Class Action
Client Alert | 5 min read | 07.21.26
Client Alert | 5 min read | 07.20.26
