1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 3 min read | 08.03.26

New Jersey Takes Aim at Algorithmic and Surveillance Pricing: What Landlords and Retailers Need to Know About the FAIR Act and the Fair Price Protection Act

On July 20, 2026, New Jersey Governor Mikie Sherrill signed the Forbidding the Algorithmic Inflation of Rent (FAIR) Act into law, making New Jersey the fourth state to regulate algorithmic rent-setting practices. Three days later, on July 23, 2026, Governor Sherrill signed the Fair Price Protection Act, which targets “surveillance pricing”—the practice of using or collecting personal data about a user and using an algorithm or artificial intelligence to charge different consumers different prices for the same products. Together, these laws represent a significant expansion of New Jersey's consumer protection framework in the algorithmic pricing context....