No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 3 min read | 10.21.26
Private Investigations Act Series: Temporal, material and territorial scope
The Private Investigations Act (PIA), which entered into force on December 16, 2024, fundamentally modernized the framework for private investigation activities in Belgium. Its implications for businesses conducting internal investigations are far-reaching.
Client Alert | 7 min read | 10.21.26
Client Alert | 4 min read | 10.20.26
California Follows New York’s Lead in Requiring AI “Synthetic Performer” Disclosures in Advertising
Client Alert | 5 min read | 10.20.26
