No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 8 min read | 10.01.25
On September 29, 2025, the U.S. Department of Commerce Bureau of Industry and Security (BIS) announced a sweeping Interim Final Rule (IFR), (the “Affiliates Rule”) expanding which entities qualify as Entity List or Military End-User entities, thereby subjecting those entities to elevated export control restrictions under the Export Administration Regulations (EAR). U.S. export restrictions applicable to entities on the Entity List, Military End-User (MEU) List, and Specially Designated Nationals and Blocked Persons (SDN List) now apply to foreign affiliates that are, in the aggregate, owned 50% or more by one or more of the aforementioned entities. An entity that becomes subject to these restrictions because of its ownership structure will be subject to the most restrictive controls that attach to any of its parent entities, regardless of ownership stakes.
Client Alert | 2 min read | 10.01.25
CPSC Shutdown Plan: Continue Enforcement, Pause Public Engagement and Civil Penalties
Client Alert | 2 min read | 10.01.25
Client Alert | 2 min read | 09.30.25
CARB Issues Preliminary List of Entities Covered by California Climate Disclosure Laws
