No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 6 min read | 07.09.26
EU Steel Overcapacity Regulation: New Permanent Measure in Force from 1 July 2026
The EU’s steel safeguard under Implementing Regulation (EU) 2019/159 expired on 30 June 2026 and has been replaced by a new permanent instrument — the EU Steel Overcapacity Regulation (Regulation (EU) 2026/1384) (the Regulation”). It imposes tariff-rate quotas and an out-of-quota duty, similarly to the steel safeguard measures that expired. The out-of-quota duty has been raised from 25% to 50% to minimize the risk of trade diversion. The Regulation reduces duty-free imports of 26 categories of steel products into the EU by an average of 47% compared with the quotas under the until recently applicable safeguard measures.
Client Alert | 1 min read | 07.08.26
CAS Board Publishes Final Rule Rescinding CAS 404, 408, 409, and 4117
Client Alert | 1 min read | 07.08.26
Crowell & Moring and Crowell GovCon Strategies at Farnborough International Airshow 2026
Client Alert | 7 min read | 07.08.26
Illinois Imposes Transparency and Safety Obligations on Frontier AI Systems
