No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 01.30.26
CMS Proposes CY 2027 Growth Rate and Changes to Risk Adjustment for Medicare Parts C and D
On January 26, 2026, the Centers for Medicare and Medicaid Services (CMS) circulated the Calendar Year (CY) 2027 Advance Notice to communicate proposed changes to Medicare Advantage (MA) capitation rates and Parts C and D payment policies. The changes are expected to be finalized in April 2026 but may be delayed. The following is a summary of the most significant proposals, with further details below:
Client Alert | 4 min read | 01.30.26
Optimum’s Shot Across the Bow: An Antitrust Challenge to Cooperation Agreements
Client Alert | 9 min read | 01.30.26
Client Alert | 7 min read | 01.29.26
ASEAN Digital Ministers' Meeting 2026: Spotlight on AI Cooperation in Asia's Rising Markets
