No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 08.12.26
Developments in Canadian Investment Treaty Practice: New FIPA Between Canada and UAE in Force
Of particular interest for investors with interests in Canada or the UAE, for counsel advising on treaty coverage, dispute strategy, or treaty design, the Canada-UAE FIPA is essential reading and the clearest evidence yet of where Canada's investment treaty practice stands over 30 years after NAFTA came into force.
Client Alert | 6 min read | 08.11.26
Client Alert | 1 min read | 08.10.26
Client Alert | 4 min read | 08.10.26
