No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 7 min read | 10.29.26
On 8 October 2026, Crowell & Moring, King's College London, and the Competition Law Center at George Washington University co-hosted the 7th EU Competition Law Conference at De Warande in Brussels. Mark Meador, Commissioner at the US Federal Trade Commission (FTC), delivered the opening keynote address, followed by four panels bringing together practitioners, regulators, academics, and in-house counsel to discuss the latest developments in EU, UK, and US competition law enforcement. Among other things, the panels examined algorithmic pricing; the European Commission's (Commission) new guidelines on exclusionary abuses under Article 102 TFEU (Article 102 Guidelines); the impact of dominant positions in merger reviews; and lessons from the enforcement of the Digital Markets Act (DMA) and the UK’s Digital Markets, Competition and Consumers Act.
Client Alert | 2 min read | 10.28.26
Debriefing to Dead Briefing: How to Avoid Dismissal by Identifying “Required” Debriefings
Client Alert | 7 min read | 10.27.26
Client Alert | 5 min read | 10.27.26
The UK Defence Footprint 2026 and the Warsaw Defence Plan: Investment, Innovation and Opportunities
