No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 4 min read | 02.05.26
EU–Brazil Mutual Adequacy: A Milestone for Global Data Flows and Latin America’s Digital Positioning
On January 27, the EU and Brazil announced their positive determination on the mutual adequacy of Brazil’s and the EU’s data privacy frameworks — confirming the growing importance of transatlantic data transfers and the EU-Mercosur relationship. This adequacy decision, while not formally tied to the EU-Mercosur trade negotiations, is a historic development that can facilitate cross-border data transfers and fuel shared economic growth driven by data-centered service sectors.
Client Alert | 4 min read | 02.04.26
DOJ Antitrust Division Issues First-Ever Award Under Whistleblower Rewards Program
Client Alert | 4 min read | 02.04.26
New York District Court Confirms Insurance Coverage Must Mean Something
Client Alert | 13 min read | 02.04.26
