No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 2 min read | 03.23.26
On March 13, a Massachusetts federal district court temporarily blocked the Trump Administration from requiring higher education institutions to respond to the Admissions and Consumer Transparency Supplement (“ACTS”) survey — a new data collection effort mandating that institutions disclose detailed admissions information regarding students’ race and sex to the federal government. In Commonwealth of Massachusetts v. Department of Education, 1:26-cv-11229 (D. Mass.), the court extended the deadline for institutions to respond to the survey from March 18th to March 25th to allow time to consider the case.
Client Alert | 1 min read | 03.23.26
Client Alert | 7 min read | 03.23.26
Client Alert | 4 min read | 03.23.26
US Section 301 Investigations: The UK Is in the Crosshairs on Forced Labour — Act Now
