No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 3 min read | 11.21.25
On November 7, 2025, in Thornton v. National Academy of Sciences, No. 25-cv-2155, 2025 WL 3123732 (D.D.C. Nov. 7, 2025), the District Court for the District of Columbia dismissed a False Claims Act (FCA) retaliation complaint on the basis that the plaintiff’s allegations that he was fired after blowing the whistle on purported illegally discriminatory use of federal funding was not sufficient to support his FCA claim. This case appears to be one of the first filed, and subsequently dismissed, following Deputy Attorney General Todd Blanche’s announcement of the creation of the Civil Rights Fraud Initiative on May 19, 2025, which “strongly encourages” private individuals to file lawsuits under the FCA relating to purportedly discriminatory and illegal use of federal funding for diversity, equity, and inclusion (DEI) initiatives in violation of Executive Order 14173, Ending Illegal Discrimination and Restoring Merit-Based Opportunity (Jan. 21, 2025). In this case, the court dismissed the FCA retaliation claim and rejected the argument that an organization could violate the FCA merely by “engaging in discriminatory conduct while conducting a federally funded study.” The analysis in Thornton could be a sign of how forthcoming arguments of retaliation based on reporting allegedly fraudulent DEI activity will be analyzed in the future.
Client Alert | 3 min read | 11.20.25
Client Alert | 3 min read | 11.20.25
Client Alert | 6 min read | 11.19.25
