No Prime Liability = No Pass-Through
Client Alert | less than 1 min read | 05.06.08
The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.
Contacts
Insights
Client Alert | 3 min read | 11.13.26
Massachusetts Trade Secret Preliminary Injunctions: Prove the Harm, Tailor the Relief
A strong trade secret claim is not a substitute for proof of irreparable harm. In Daikin Applied Americas Inc. v. Russo, No. SJC-13881 (Mass. Oct. 14, 2026), the Massachusetts Supreme Judicial Court held that likely success on a misappropriation claim does not create a presumption of irreparable harm. The court grounded its ruling in both the Massachusetts Uniform Trade Secrets Act and the traditional equitable principles the statute incorporates. It required a case-specific showing that the requested relief would prevent harm that a final judgment could not adequately remedy.
Client Alert | 1 min read | 11.12.26
SBA Announces Doubling Veteran Contracting Target to 10% for FY 2027, but Questions Remain
Client Alert | 6 min read | 11.12.26
Client Alert | 2 min read | 11.11.26
President Trump Nominates Peter Feldman to Serve as CPSC Chairman and Commissioner
