1. Home
  2. |Insights
  3. |No Prime Liability = No Pass-Through

No Prime Liability = No Pass-Through

Client Alert | less than 1 min read | 05.06.08

The Court of Federal Claims in Harper/Nielsen Dillingham, Builders v. U.S. (Apr. 29, 2008) denied a contractor's suit against the government in which it sought to pass through subcontractor claims for cost increases caused by government delays. The court acknowledged that the "Severin doctrine" allows such pass-through claims when the prime contractor is potentially liable to its subcontractor for the damages, but here found the prime could not be liable because the subcontract included an "iron-bound bar" against such liability due to a "no damage for delay" clause.

Insights

Client Alert | 3 min read | 04.24.24

Digging Deeper: “American Made” Claims From the Tenth Circuit’s Decision in I DIG Texas v. Kerry Creager Diverge from FTC Guidance

On April 12, 2024, the Tenth Circuit issued a decision in I DIG Texas LLC v. Kerry Creager, which analyzed country-of-origin claims in a manner that diverged from the well-established Federal Trade Commission’s “Made in USA” policy....